Terms & Conditions
Website and Google Business Profile Services Terms
Last updated September 25, 2026These Website and Google Business Profile Services Terms (the “Terms”) are a binding agreement between the customer accepting them (“Client,” “you,” or “your”) and Tyler Silverman, an individual (“Provider,” “we,” “us,” or “our”).
Provider operates the website located at getabusinesswebsite.com (the “Site”). The domain name getabusinesswebsite.com and the name GetABusinessWebsite.com are website and marketing identifiers only. They are not a separate legal entity or the contracting party.
These Terms govern all website design, hosted website, maintenance, support, Google Business Profile, local search and related services that Provider supplies (collectively, the “Services”). An estimate, proposal, checkout page, invoice, subscription selection, statement of work or other written service description accepted by Provider is an “Order.”
By signing or accepting an Order, clicking an acceptance box, submitting payment, authorizing recurring charges, accessing a preview after purchase or using any paid Service, you agree to these Terms. If you accept for a company or other organization, you represent that you have authority to bind it.
The Services are offered solely for business and commercial purposes, not for personal, family or household use.
1. Orders and Scope
The applicable Order identifies the Services, fees, billing cycle and any specific deliverables. These Terms and the Order form the entire service agreement.If they conflict, the Order controls only as to the specific commercial term it expressly changes. These Terms control regarding ownership, platform rights, disclaimers, indemnification, liability and disputes unless the Order expressly identifies the provision being changed and Provider approves that change in writing.
Only work expressly listed in an Order is included. Additional pages, features, integrations, content entry, campaigns, accessibility remediation, custom code, migrations, emergency work, Google Business Profile appeals or other work may require a separate fee or Order.
Provider may use employees, contractors, licensors, hosting vendors, artificial intelligence tools and other service providers to perform the Services.
Project plans, launch dates, response times, estimates, previews, demos and forecasts are estimates only unless an Order expressly establishes a binding service level. All schedules depend on Client’s timely cooperation, approvals, access, materials and payment. Client delay automatically extends deadlines and does not suspend fees.
2. Free Demos and Proposals
Any free demo, mockup, preview, sample, concept, proposal or speculative work is provided only for evaluation.It remains Provider property, may contain placeholder or third-party content and may not be copied, published, used, modified, shared with another developer or used to create a similar website unless Client purchases the applicable Service and remains authorized under Section 8.
Provider has no obligation to preserve or complete a demo.
3. Client Responsibilities
Client will promptly provide complete and accurate information, content, instructions, credentials, approvals, business documentation and access reasonably needed to perform the Services.Client will designate one person authorized to provide instructions and approvals. Provider may rely on instructions from that person or from an account or email address reasonably associated with Client.
Client is responsible for reviewing all drafts, profile edits, business facts, pricing, offers, contact information, legal statements and final deliverables.
Unless an Order provides a different period, an item is deemed approved if Client does not provide specific written corrections within five business days after delivery or if Client publishes, uses or directs Provider to publish it. Approval does not transfer ownership of the website or Provider Platform.
Client will maintain current backups of systems or data to which it gives Provider access, maintain secure credentials and multifactor authentication where available, promptly remove access that is no longer appropriate and notify Provider of suspected unauthorized access.
Client remains responsible for all activity in its accounts and for the acts and omissions of its owners, employees, agents and contractors.
4. Website Services
Website design, construction, hosting, updates, maintenance, security, analytics, forms and support are provided only to the extent listed in the Order.Provider may select and change the technical architecture, hosting environment, content management tools, themes, plugins, vendors, security controls and delivery methods used to operate the website, provided the core paid Service remains materially available.
Included updates and revisions are limited to the amount and type stated in the Order. Unused update time or work does not roll over.
Material redesigns, new functionality, integrations, copywriting, media production, data entry and work caused by Client or third-party changes are outside the scope unless agreed to in writing. Provider may charge its then-current rate for additional work.
Provider will use commercially reasonable efforts to support current versions of common browsers and devices but does not promise identical presentation or functionality across every browser, device, operating system, accessibility technology, network or future software version.
Hosting, email, forms, analytics, integrations and security depend partly on third parties and may be interrupted, delayed, changed or discontinued.
Unless an Order expressly includes a written service level, Provider does not guarantee uptime, backup frequency, recovery time, response time, malware prevention or uninterrupted access. No system is completely secure.
Client will not use the website to collect or process payment-card data, protected health information, government identifiers or other regulated or highly sensitive information unless Provider expressly agrees in a signed Order identifying the required safeguards.
Domains are separate from the hosted website. A domain registered and paid for directly by Client remains Client’s property, subject to the registrar’s terms. Client is responsible for renewals, accurate registrant information and continued access.
If Provider registers or manages a domain as a convenience, ownership and any transfer right are determined by the Order and full payment of all amounts due.
Termination of the website Service does not transfer the hosted website merely because Client owns the domain.
5. Google Business Profile Management
Client appoints Provider as its authorized agent to access and manage the Google Business Profile and related Google accounts identified in the Order.Client represents that it owns, operates or is duly authorized to represent each listed business and location. Client should retain the primary owner role and grant Provider only the access Provider reasonably requests.
Google, not Provider, controls profile eligibility, verification, content approval, visibility, ranking, reviews, edits, account restrictions, suspensions, reinstatement, appeals, features, policies and support.
Google may change, restrict or remove any profile, feature, content or account access without notice.
Provider does not guarantee:
- Profile creation or approval
- Verification or continued verification
- Search or map rankings
- Profile visibility
- Website traffic, telephone calls or leads
- Review removal or review volume
- Protection from suspension or delisting
- Reinstatement following a suspension
- The success of an appeal
- Any particular response or processing time from Google
Client is solely responsible for its eligibility and for discrepancies between its profile, actual operations, public records, website, signage and business documentation.
Provider may decline or reverse an instruction that Provider reasonably believes could violate Google policy, applicable law or third-party rights.
A profile delay, rejection, ranking change, feature loss, delisting, suspension, account restriction or unsuccessful appeal caused by Google, Client information, Client conduct, a prior manager, a competitor, public edits or another third party is not a breach by Provider and does not excuse fees already incurred.
Unless expressly included in the Order, suspension diagnosis, evidence preparation, appeals, additional reviews and profile recovery work are separately billable.
Client will not ask Provider to:
- Create or purchase fake reviews
- Gate negative reviewers
- Impersonate customers
- Misstate a business location
- Add unauthorized keywords to a business name
- Use an ineligible address
- Create duplicate or misleading profiles
- Engage in deceptive or prohibited conduct
Profile Posts and Content
Client authorizes Provider to draft, schedule, publish, edit and remove Google Business Profile posts, updates, offers, photographs, responses, questions and answers and other content within the scope of the Order (“Profile Content”).Provider acts only as Client’s service provider and authorized agent. Client is the business represented, the advertiser and the publisher responsible for Profile Content.
Client is solely responsible for the truth, substantiation, legality, pricing, expiration dates, disclosures, intellectual property rights and business consequences of Profile Content, including content approved, supplied, requested or deemed approved by Client.
To the maximum extent permitted by law, Client assumes all risk of and releases Provider and its related parties from liability arising from or relating to:
- Google’s rejection, deletion, delisting, suspension or restriction of a profile
- Verification or reverification requirements
- An account restriction or account lock
- Ranking or visibility changes
- Lost reviews, posts, photos, messages, data, profile ownership or account access
- Google enforcement or other platform decisions
- Profile Content or responses posted for Client
- Public reaction to Profile Content
- Customer reliance, complaints, claims, reviews or regulatory attention relating to Profile Content
- Unauthorized or inaccurate edits made by Google, Client, another manager, a user, a competitor or another third party
6. Marketing and Performance
Search engine optimization, local search, reputation management, analytics, advertising and other marketing Services involve professional judgment and changing third-party systems.Provider does not control search engines, maps, directories, social networks, reviewers, competitors, algorithms, market conditions or prospective customers.
Provider makes no promise of any ranking, placement, impression, visit, call, lead, sale, revenue, review, conversion or return on investment. Past performance, examples, projections and estimates do not guarantee future results.
Analytics and reports may rely on third-party data, sampling, attribution models, consent settings, blocked tracking or estimates and may be delayed or inaccurate. Client remains responsible for business decisions made using reports.
Advertising spend, software charges, stock media, premium plugins, directory charges and other third-party costs are separate unless the Order expressly includes them.
7. Fees Billing Renewal and Cancellation
Client will pay the setup fees, recurring fees, usage charges, third-party costs, taxes and other amounts stated in the Order.Setup and project fees compensate Provider for reserving capacity and performing work and are nonrefundable once paid, except where applicable law expressly requires otherwise.
Recurring fees are charged in advance. Client authorizes Provider and its payment processor to store the selected payment method and charge it for all amounts due, including renewals, approved additional work, taxes, late charges, chargeback costs and restoration fees.
Unless an Order states otherwise, each monthly or annual subscription automatically renews for successive periods of the same length until canceled.
Client may cancel through an online cancellation method made available by Provider or by emailing tyler@getabusinesswebsite.com from an email address associated with the account.
Cancellation is effective at the end of the current paid billing period unless the Order contains a minimum term.
Fees are not prorated or refunded for partial periods, unused capacity, Client delay, suspension, downgrade or early cessation of use.
Provider may change recurring fees by giving at least 30 days’ notice, with the change effective on the first renewal following the notice period. Client’s continued use after the effective date constitutes acceptance. Client’s remedy is to cancel before the new price takes effect.
This provision does not limit any longer notice or consent requirement imposed by applicable law.
An invoice or charge not disputed in specific written detail within 15 days after the invoice or charge date is deemed accepted to the fullest extent permitted by law.
Overdue amounts accrue interest at 1.5% per month or the maximum lawful rate, whichever is lower. Client will reimburse Provider’s reasonable collection costs.
Provider may suspend Services, disable the website, revoke access, pause work and withhold deliverables if an amount is overdue, a payment method fails or a charge is reversed.
Client will contact Provider and provide a reasonable opportunity to investigate a billing issue before initiating a chargeback.
A chargeback or payment reversal does not cancel the underlying debt or subscription. A knowingly false, abusive or unauthorized chargeback is a material breach. Client is responsible for processor fees and reasonable costs caused by it to the extent permitted by law.
8. Platform and Website Ownership
The website is a hosted service operating on Provider’s proprietary platform.The “Provider Platform” includes Provider’s proprietary and licensed hosting environment, software, content management systems, code, source code, object code, databases, schemas, themes, templates, layouts, design systems, components, configurations, automations, processes, methods, documentation, accounts, know-how, improvements and other technology used to create, operate, maintain or deliver websites and Services.
THE WEBSITE IS LICENSED AS A SERVICE AND IS NOT SOLD. IT IS NOT A WORK MADE FOR HIRE.
Except for Client Materials defined below, Provider and its licensors retain all right, title and interest in the Provider Platform, the hosted website, its design and arrangement, Provider-created materials, demos, drafts and all related intellectual property.
Payment of setup, design, hosting, maintenance or subscription fees does not transfer ownership.
While Client’s account is fully paid, active and compliant with the Agreement, Provider grants Client a limited, revocable, nonexclusive, nontransferable and nonsublicensable license to access and publicly display the hosted website solely for Client’s own business.
The license is conditioned on continued payment and automatically ends upon cancellation, expiration, termination, chargeback or suspension for nonpayment or breach.
When the license ends, Provider may immediately:
- Disable or remove the website
- Disconnect the website from a domain
- Revoke administrative access
- Stop hosting and maintenance
- Stop backups and security services
- Disable forms, analytics and other functions
- Delete website data and configurations
- The hosted website
- A clone or copy of the website
- An exportable or self-hosted version
- Source code or object code
- Build files
- Templates or themes
- Plugins
- Databases
- Platform accounts
- Website configurations
- Design files
- Provider credentials
Client may not copy, scrape, download, reproduce, frame, reverse engineer, decompile, disassemble, circumvent access controls for, create derivative works from, resell, sublicense, transfer or direct another person to recreate the Provider Platform or hosted website, except to the limited extent a restriction is prohibited by law.
Client will not use screenshots, demos, previews or access to commission or build a substantially copied website. All rights not expressly granted are reserved.
“Client Materials” means logos, trademarks, photographs, videos, text, data and other materials that Client owned before providing them to Provider or independently obtained from a third party.
As between the parties, Client retains ownership of Client Materials.
Client grants Provider a worldwide, royalty-free license to host, reproduce, edit, adapt, display, distribute and otherwise use Client Materials as reasonably necessary to provide, demonstrate, secure, improve and support the Services.
Upon written request made while the account is active, Provider will use reasonable efforts to return available original Client Materials supplied by Client. This does not include the hosted website, Provider-created materials or Provider Platform.
Third-party fonts, images, plugins, software, integrations and other materials remain subject to their owners’ terms and may not be transferable.
Provider may identify Client by name and logo and display publicly available screenshots or links as part of Provider’s portfolio and marketing unless Client objects in writing.
Client grants Provider a perpetual, irrevocable, royalty-free right to use suggestions and feedback without restriction or compensation.
9. Client Content Compliance and Approvals
Client represents, warrants and covenants that it owns or has all rights and permissions needed for Client Materials, business information, customer lists, testimonials, reviews, claims, offers, trademarks, photos and instructions.Client represents that these materials are accurate and not misleading and that Provider’s authorized use will not violate law, privacy rights, publicity rights, contractual obligations or intellectual property rights.
Client is responsible for substantiating all product, service, price, performance, health, financial, licensing and promotional claims.
Client is solely responsible for laws and industry rules applicable to its business and online operations, including:
- Business and professional licensing
- Advertising and consumer protection
- Privacy and cookies
- Data collection and retention
- Website accessibility
- Email and text-message marketing
- Contests and promotions
- Ecommerce and refunds
- Taxes
- Regulated products
- Professional services
Any privacy policy, terms, accessibility text, consent language or other legal-style content supplied by Provider is a convenience template only and must be reviewed by Client’s attorney.
Unless a signed Order expressly states otherwise, the Services do not include an accessibility audit, legal compliance audit or warranty of compliance with the Americans with Disabilities Act, Web Content Accessibility Guidelines, California Consumer Privacy Act, California Privacy Rights Act or another law or standard.
Client will promptly notify Provider of any demand, complaint or alleged violation relating to the website or Google Business Profile.
Provider may use generative artificial intelligence and automated tools to assist with drafts, images, summaries, coding or analysis.
Client must review and approve outputs for accuracy, rights, bias, suitability and legal compliance before publication.
Provider may refuse or remove content that it reasonably believes is unlawful, harmful, deceptive, infringing, insecure or contrary to third-party rules.
10. Privacy Confidentiality and Data
Provider’s privacy policy, as posted on the Site, describes Provider’s handling of personal information collected through the Site and Services.Client authorizes Provider to process Client data and provide it to contractors, licensors, hosting providers, payment processors, analytics providers, Google and other service providers as reasonably necessary to perform the Services, protect the parties, enforce the Agreement and comply with law.
Each party will use reasonable care to protect the other party’s nonpublic information that is identified as confidential or reasonably should be understood as confidential.
This obligation does not apply to information that the receiving party can document:
- Was lawfully known without restriction
- Becomes public without breach
- Is received lawfully from another source
- Is independently developed
Provider may create and use aggregated or deidentified information that does not reasonably identify Client or an individual to operate, secure, analyze and improve its business and Services.
Provider does not guarantee that data or Client Materials will be retained after termination.
Subject to legal obligations and ordinary backup cycles, Provider may delete account data, website data and Client Materials 30 days after termination, cancellation or suspension. Provider may charge for restoration if restoration is possible.
11. Third-Party Services
Third-party platforms and services, including Google, domain registrars, hosting infrastructure, payment processors, analytics tools, form providers, email providers, plugins and stock-media providers, are not controlled by Provider.Their terms, fees, APIs, functionality, policies, availability and data practices may change.
Client agrees to their applicable terms and is responsible for accounts and fees in Client’s name.
Provider is not responsible for a third party’s acts or omissions, outages, security incidents, account decisions, data loss, price changes, policy enforcement, feature changes, termination or failure to provide support.
Provider may replace, remove or stop supporting an integration if it becomes unavailable, insecure, unlawful, commercially unreasonable or incompatible.
12. Suspension and Termination
Client may cancel recurring Services as provided in Section 7, subject to any minimum term stated in the Order.Provider may suspend or terminate any Service immediately, with or without prior notice, if Client:
- Fails to pay
- Reverses or disputes a valid charge
- Breaches the Agreement
- Creates security, legal, reputational or platform risk
- Abuses Provider personnel
- Supplies deceptive or unlawful instructions
- Violates third-party terms
- Causes continued performance to become unlawful or commercially impracticable
Suspension does not waive amounts due or extend a billing period.
Provider may charge its then-current restoration fee and require payment of all outstanding amounts before restoring a Service. Restoration is not guaranteed.
Upon termination, all licenses granted to Client end, unpaid amounts become immediately due and Provider may take the actions described in Section 8.
Sections that by their nature should survive will survive, including payment, ownership, restrictions, confidentiality, disclaimers, indemnification, liability, disputes and general provisions.
13. Disclaimers
TO THE MAXIMUM EXTENT PERMITTED BY LAW, THE SERVICES, PROVIDER PLATFORM, HOSTED WEBSITE, DEMOS, DELIVERABLES, REPORTS AND SUPPORT ARE PROVIDED “AS IS” AND “AS AVAILABLE.” CLIENT USES THEM AT ITS OWN RISK.PROVIDER DISCLAIMS ALL EXPRESS, IMPLIED, STATUTORY AND OTHER WARRANTIES, INCLUDING WARRANTIES OF MERCHANTABILITY, FITNESS FOR A PARTICULAR PURPOSE, TITLE, NON-INFRINGEMENT, ACCURACY, RESULTS, QUIET ENJOYMENT AND WARRANTIES ARISING FROM COURSE OF DEALING OR USAGE OF TRADE.
Provider does not warrant that any Service will be uninterrupted, secure, error-free, accessible, compliant, compatible or free of harmful components; that data will be accurate, complete or preserved; that defects will be corrected; or that any website, Google Business Profile, ranking, review, campaign or business result will meet Client’s expectations.
No oral or written statement creates a warranty unless expressly included as a warranty in a signed Order.
Without limiting the foregoing, Provider has no liability for a Google Business Profile or related account being:
- Rejected
- Unverified or reverified
- Delisted
- Disabled
- Suspended
- Restricted
- Deleted
- Merged
- Duplicated
- Reranked
- Otherwise changed by Google
Provider has no liability for Profile Content, posts, offers, responses or other material published for Client or at Client’s direction.
Client accepts these risks as an essential condition of the Services.
14. Indemnification
Client will defend, indemnify and hold harmless Provider and its affiliates, licensors, contractors, payment processors and their respective owners, personnel and agents from and against every third-party claim, demand, investigation, proceeding, loss, liability, judgment, settlement, penalty, fine, damage, cost and reasonable attorney fee arising out of or relating to:- Client Materials
- Client’s business information or customer data
- Client’s instructions, claims, products or services
- Client’s business or website use
- Client’s Google Business Profile
- Profile Content, posts, offers or review responses
- Client reviews, communications or advertising
- Client’s dealings with customers
- A profile suspension, delisting, restriction, verification, appeal or other Google action
- Client’s breach of the Agreement
- Client’s violation of law or third-party terms
- Infringement of intellectual property rights
- Violation of privacy, publicity, accessibility, consumer or communication rights
- Client’s negligence, fraud, willful misconduct or security failure
- Acts or omissions of Client’s personnel, agents or contractors
Client will cooperate at its expense.
Client may not settle a claim in a manner that admits fault by, imposes an obligation on or fails to fully release an indemnified party without Provider’s written consent.
Provider may participate with separate counsel at its own expense, except Client will pay that expense when separate counsel is reasonably required by a conflict of interest.
15. Limitation of Liability
TO THE MAXIMUM EXTENT PERMITTED BY LAW, PROVIDER AND ITS AFFILIATES, LICENSORS, CONTRACTORS AND PERSONNEL WILL NOT BE LIABLE FOR ANY INDIRECT, INCIDENTAL, SPECIAL, CONSEQUENTIAL, EXEMPLARY, ENHANCED OR PUNITIVE DAMAGES.This exclusion includes lost profits, revenue, business, goodwill, savings, opportunities, customers, leads, rankings, reviews or data; costs of substitute services; website or profile downtime; and third-party claims.
The exclusion applies even if Provider was advised that such damages were possible and regardless of the theory of liability.
TO THE MAXIMUM EXTENT PERMITTED BY LAW, THE TOTAL AGGREGATE LIABILITY OF PROVIDER AND ALL RELATED PARTIES FOR ALL CLAIMS ARISING OUT OF OR RELATING TO AN ORDER, THE SERVICES OR THE AGREEMENT WILL NOT EXCEED THE FEES ACTUALLY PAID TO PROVIDER FOR THE SPECIFIC AFFECTED SERVICE DURING THE ONE MONTH IMMEDIATELY BEFORE THE EVENT FIRST GIVING RISE TO LIABILITY.
If Client paid no fees for the affected Service, the maximum liability is $100.
This is a cumulative cap, not a separate cap for each claim.
The exclusions and cap apply even if a remedy fails of its essential purpose.
They do not limit Client’s payment obligations, Client’s indemnification obligations or Client’s liability for misuse of Provider intellectual property, fraud, willful misconduct or breach of Sections 8 or 10.
If applicable law does not allow a particular exclusion or limitation, it applies to the greatest extent permitted by law.
16. Dispute Resolution and Arbitration
Before filing a claim, a party must send written notice describing the facts, legal basis and requested relief and allow 30 days for good-faith informal resolution.A limitations period is suspended during that 30-day period.
Notices to Provider must be sent to tyler@getabusinesswebsite.com.
The parties will conduct an individual telephone or video settlement conference if either party requests one.
Except for an eligible individual claim in small claims court or a request for temporary or preliminary relief to protect intellectual property, confidential information, accounts or systems, every dispute arising out of or relating to the Agreement, Services, billing or the parties’ relationship will be resolved through final and binding individual arbitration administered by the American Arbitration Association under its Commercial Arbitration Rules.
The Federal Arbitration Act governs this section.
The arbitration will be conducted by one arbitrator in Los Angeles County, California, although the arbitrator may allow remote proceedings.
The arbitrator has exclusive authority to decide questions concerning the formation, scope, validity, enforceability and arbitrability of the Agreement, except that a court will decide the enforceability of the class-action waiver below.
Judgment on the award may be entered in any court with jurisdiction.
Fees will be allocated under the applicable AAA rules. Each party will bear its own attorney fees unless a statute or another express provision of the Agreement requires otherwise.
EACH PARTY WAIVES A JURY TRIAL AND AGREES THAT CLAIMS MAY BE BROUGHT ONLY IN AN INDIVIDUAL CAPACITY, NOT AS A PLAINTIFF, CLAIMANT OR CLASS MEMBER IN ANY CLASS, COLLECTIVE, CONSOLIDATED, PRIVATE-ATTORNEY-GENERAL OR REPRESENTATIVE ACTION.
An arbitrator may award relief only to the individual party seeking it and only to the extent necessary to resolve that party’s claim.
If this waiver is finally held unenforceable for a particular claim or remedy, that claim or remedy will be severed and resolved exclusively in the courts identified below. All remaining claims will be arbitrated.
To the fullest extent permitted by law, a claim must be commenced within one year after the claimant knew or reasonably should have known of the facts giving rise to it or it is permanently barred.
If arbitration is unavailable or a claim is properly in court, the state and federal courts located in Los Angeles County, California will have exclusive jurisdiction.
Each party consents to personal jurisdiction and waives any objection to venue in those courts.
California law governs without regard to conflict-of-laws principles.
17. General Terms
Provider is an independent contractor.Nothing creates a partnership, franchise, fiduciary, employment, joint venture or agency relationship other than the limited Google authorization described in Section 5.
No person other than the parties and indemnified parties is an intended third-party beneficiary.
Provider may assign the Agreement or any right to an affiliate, successor, purchaser, financing source or service operator.
Client may not assign, delegate, resell, sublicense or transfer the Agreement, an account or any right without Provider’s prior written consent. Any prohibited transfer is void.
Provider is not liable for delay or failure caused by events beyond its reasonable control, including natural disasters, fire, severe weather, disease, labor disputes, war, terrorism, civil disorder, utility or internet failure, cyberattack, vendor failure, platform outage, government action, supply shortage or third-party policy or system changes.
Notices may be delivered electronically.
Client consents to receive agreements, invoices, disclosures, renewal and price notices and other communications at the email address associated with the account.
Client will keep its contact and billing information current.
Notice to Client is effective when sent. Notice to Provider is effective when actually received at tyler@getabusinesswebsite.com.
Provider may update these Terms prospectively.
Material changes will be posted or sent to Client and will apply on the stated effective date, no earlier than the next renewal or 30 days after notice, unless a change is required sooner by law, security or a third-party platform.
Continued use or renewal after the effective date constitutes acceptance.
Changes do not retroactively alter a dispute that arose before notice.
The Agreement is the entire agreement concerning its subject and supersedes prior discussions, statements and proposals.
Client acknowledges that it has not relied on any promise not expressly included in the Agreement.
An amendment or waiver by Provider must be in writing and signed by Provider, except for updates permitted above.
Failure to enforce a provision is not a waiver.
If a provision is invalid or unenforceable, it will be enforced to the maximum lawful extent and modified only as necessary to reflect its purpose. The remaining provisions remain effective.
Headings are for convenience only. “Including” means “including without limitation.”
Electronic acceptance and signatures have the same effect as originals. The Agreement may be accepted in counterparts.
18. Contact
Questions, legal notices, billing disputes and cancellation requests may be sent to:tyler@getabusinesswebsite.com
The Site may provide additional contact methods, but only the foregoing email address is designated for legal notices under the Agreement.